Who is Patricia McQuaid?

Patricia McQuaid is a vice-chair at the Condominium Authority Tribunal with 672 decisions on record from 2007 to 2026. Key areas include other tribunals, administrative law, real estate law.

What tribunal does Patricia McQuaid sit on?

Patricia McQuaid has sat on Alcohol and Gaming Commission of Ontario and Ontario Licence Appeal Tribunal and Condominium Authority Tribunal and Ontario Fire Safety Commission and Ontario Animal Care Review Board.

What areas of law does Patricia McQuaid decide?

Patricia McQuaid's most common areas include Other Tribunals (641 decisions), Administrative Law (588 decisions), Real Estate Law (78 decisions). Patricia McQuaid has handled 672 decisions across 7 areas.

How many decisions has Patricia McQuaid made?

Patricia McQuaid has 672 decisions on record from 2007 to 2026 across 5 tribunals.

Who frequently appears before Patricia McQuaid?

Representatives who frequently appear before Patricia McQuaid include Richard Kulis, Richard Kulis, Phillip Morris.

/Adjudicator

minicounsel

Other Tribunals

Administrative Law

Real Estate Law

Statutory Accident Benefits Schedule matters (SABS)

Human Rights

Construction Law

Civil Litigation - Plaintiff

Patricia McQuaid

Vice-Chair·Condominium Authority Tribunal·Since 2007

OCAT OACRB OFSC AGCO OLAT

672

cases · 20 yrs · AGCO, OLAT, OCAT, OFSC, OACRB

Trial

Motion

Costs

Appeal

Sentencing

Vice-Chair· 391Vice-Chair· 136Vice-Chair· 34Vice Chair· 28Vice-Chair, AGCO· 19VICE -CHAIR· 11Member· 9Vice-Chair· 8

Symon Zucker

In Private Practice91 cases1985–2026

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalApr 22, 2014

Consent order issued imposing terms and conditions on motor vehicle dealer registrations in lieu of revocation.

The Registrar issued a Notice of Proposal to revoke the registrations of a motor vehicle dealership and its principals.

The parties reached a settlement and applied for a consent order without a hearing.

The Licence Appeal Tribunal issued the consent order, imposing extensive terms and conditions on the registrants regarding disclosure, record-keeping, consumer complaints, and mandatory education, in lieu of revocation.

Switzer Motors Ltd v. Registrar, Motor Vehicle Dealers Act 2002, 2014 CanLII 23588

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalFeb 28, 2014

Consent order issued resolving appeal of proposal to revoke travel agent registration.

The applicant travel agent appealed a Notice of Proposal by the Registrar to revoke its registration under the Travel Industry Act, 2002 for failing to file financial statements and working capital non-compliance.

The parties reached a settlement and requested a consent order disposing of the appeal without a hearing.

The Licence Appeal Tribunal issued the consent order incorporating the Minutes of Settlement, which required the applicant to file annual financial statements, maintain minimum working capital, and comply with other regulatory requirements.

Thames Valley Tours and Travel Inc. o/a Woodstock Travel v. Registrar, Travel Industry Act, 2002, 2014 CanLII 10708

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJan 28, 2014

Consent order issued resolving appeal of Registrar's proposal to refuse motor vehicle dealer registration.

The applicants appealed a Notice of Proposal by the Registrar to refuse their registration under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and requested a consent order without a hearing pursuant to section 4.1 of the Statutory Powers Procedure Act.

The Licence Appeal Tribunal issued the consent order, incorporating the agreed-upon terms and conditions regarding the applicants' registration, business practices, record-keeping, and financial responsibilities.

Tahir Dar v. Registrar, Motor Vehicle Dealers Act 2002, 2014 CanLII 7959

Symon Zucker

In Private Practice91 cases1985–2026

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJan 23, 2014

Consent order issued imposing conditions on motor vehicle dealer registrations to resolve revocation proposal.

The applicants appealed a Notice of Proposal by the Registrar to revoke their registrations under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and requested a consent order without a hearing pursuant to section 4.1 of the Statutory Powers Procedure Act.

The Licence Appeal Tribunal issued the consent order, imposing conditions on the applicants' registrations, including prohibitions on false advertising, requirements for Registrar approval of advertisements, and restrictions on the involvement of unregistered individuals in the dealership.

Hussein Shahnematollah-Yazd and Premium Cars Wholesale Ltd v. Registrar, Motor Vehicle Dealers Act, 2002, 2014 CanLII 7974

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJan 22, 2014

Consent Order issued imposing conditions on motor vehicle dealer registration without a hearing.

The applicant appealed a Notice of Proposal by the Registrar to refuse registration under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and requested a Consent Order without a hearing.

The Licence Appeal Tribunal issued the Consent Order, incorporating the settlement terms, which included conditions that the applicant not be a partner, shareholder, officer, or director of a dealership, not provide financing, and provide full disclosure to the Registrar.

Ramadan v. Registrar, Motor Vehicle Dealers Act 2002, 2014 CanLII 2449

Monetary penalty for permitting drunkenness set aside as Registrar failed to prove licensee's knowledge.

The Registrar of Alcohol and Gaming imposed a monetary penalty on the applicant licensee for allegedly permitting drunkenness and disorderly conduct by three patrons, contrary to s. 45(1) of Regulation 719/90 under the Liquor Licence Act.

On appeal, the Licence Appeal Tribunal found that while some patrons may have been intoxicated or acted disorderly, the Registrar failed to prove on a balance of probabilities that the licensee knew or ought to have known of the drunkenness or disorderly conduct in the circumstances.

The Tribunal directed the Registrar to set aside the order of monetary penalty.

2316826 Ontario Inc. o/a Mimico Pub and Grill v. Registrar of Alcohol and Gaming, 2014 CanLII 2477

Tamara Brooks

Practising Law - Employed68 cases2010–2020

Jerry Levitan

101 cases2001–2025

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalNov 25, 2013

Liquor licence application approved subject to consent conditions after objectors withdrew their objections.

The applicant appealed a Notice of Proposal by the Registrar of Alcohol and Gaming regarding a liquor licence application.

Following a pre-hearing, the applicant and public interest objectors agreed to a set of conditions to attach to the licence.

The objectors withdrew their objections, and the Tribunal approved the liquor licence application subject to the agreed-upon conditions.

Sweet Estoril Bakery and Pastry Inc. v. Registrar of Alcohol and Gaming, 2013 CanLII 78241

Julian Porter

13 cases2002–2022

Gregory G. Goulin

1 case2013–2013

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalOct 8, 2013

Consent order issued concluding appeal of registration revocation based on 10-year undertaking not to apply.

The applicants appealed a Notice of Proposal by the Registrar to revoke their registrations as a motor vehicle dealer and salespersons.

The parties reached a settlement and requested a Consent Order without a hearing under section 4.1 of the Statutory Powers Procedure Act.

The Tribunal ordered the proceedings concluded on the basis of the settlement, which included the cancellation of the registrations and undertakings by the applicants not to apply for registration for a period of 10 years.

Clarke Chevrolet Buick GMC LTD. v. Registrar, Motor Vehicle Dealers Act 2002, 2013 CanLII 65429

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalOct 1, 2013

Consent order issued resolving appeal of Registrar's proposal to refuse motor vehicle dealer registration.

The applicants appealed a Notice of Proposal by the Registrar to refuse their registration under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and requested a consent order without a hearing pursuant to section 4.1 of the Statutory Powers Procedure Act.

The Licence Appeal Tribunal issued the consent order, incorporating the agreed terms and conditions, which included strict requirements for disclosing material facts about vehicles, complying with the Code of Ethics, and completing an educational course.

Jainarine v. Registrar, Motor Vehicle Dealers Act 2002, 2013 CanLII 65435

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalAug 28, 2013

Consent order issued resolving appeal of proposal to revoke travel agent registration.

The Registrar issued a Notice of Proposal to revoke the registration of Happy Travellers Inc. as a travel agent for failing to maintain a trust account and file financial statements.

The applicant appealed to the Licence Appeal Tribunal.

The parties reached a settlement and requested a consent order without a hearing.

The Tribunal issued the consent order, incorporating the Minutes of Settlement which required the applicant to submit monthly trust reconciliations, file annual financial statements, and maintain minimum working capital.

Happy Travellers Inc. v. Registrar, Travel Industry Act 2002, 2013 CanLII 58476

Evelyn Spence

Practising Law - Employed2 cases2013–2013

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJul 31, 2013

Appeal allowed; retirement home licence issued subject to agreed conditions following settlement between the parties.

The applicant appealed a Notice of Decision by the Registrar of the Retirement Homes Regulatory Authority refusing to issue a licence.

At the pre-hearing, the parties presented a settlement agreement wherein the Registrar agreed to issue the licence subject to specific conditions.

The Tribunal reviewed the agreement, confirmed the applicant's understanding and capacity to comply, and ordered the Registrar to issue the licence subject to the agreed conditions.

2321772 Ontario Inc. o/a Bel-Marine Retirement Residence v. Registrar, Retirement Homes Regulatory Authority, 2013 CanLII 51153

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJul 24, 2013

Consent order granted attaching terms and conditions to motor vehicle salesperson's registration without a hearing.

The applicant and the Registrar under the Motor Vehicle Dealers Act, 2002 applied for a consent order without a hearing pursuant to section 4.1 of the Statutory Powers Procedure Act.

The Licence Appeal Tribunal granted the order, attaching agreed-upon terms and conditions to the applicant's registration as a motor vehicle salesperson, including ongoing compliance obligations and a 4-month expiration for the order.

Mark Lensink v. Registrar, Motor Vehicle Dealers Act, 2002, 2013 CanLII 45557

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJul 12, 2013

Consent order issued attaching conditions to a private club's liquor licence.

The applicant, The Spoke Club, and the added party, the City of Toronto, applied for a consent order without a hearing regarding the applicant's liquor licence.

The Registrar of Alcohol and Gaming took no position.

The Licence Appeal Tribunal issued the consent order, attaching conditions to the liquor licence concerning its operation as a private club, restaurant requirements, patron and public safety, and neighbourhood impact.

The Spoke Club v. Registrar of Alcohol and Gaming, 2013 CanLII 45549

Gena Argitis

Not Practising Law - Employed19 cases2006–2015

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJul 11, 2013

Appeal for delayed closing compensation dismissed; email notice of delay deemed effective despite postal strike.

The applicant appealed a decision by Tarion Warranty Corporation denying a claim for delayed closing compensation.

The builder had sent notice of the delay by registered mail, which was delayed due to a postal strike, and subsequently sent an email notice.

The applicant argued the email was not a permitted form of communication under the addendum and was not received.

The Tribunal found that the applicant had provided his email address to the builder, regularly communicated via email, and that the email notice satisfied the requirement to re-send notice by another means.

The appeal was dismissed and the claim denied.

7995 v. Tarion, 2013 CanLII 45546

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJul 9, 2013

Consent order issued resolving appeal of travel wholesaler registration revocation upon agreed compliance terms.

The Registrar issued a Notice of Proposal to revoke the registration of a travel wholesaler for failing to file financial statements, lacking a properly designated manager, and failing to operate from an approved dwelling.

The applicant appealed to the Licence Appeal Tribunal.

The parties reached a settlement and requested a consent order without a hearing under section 4.1 of the Statutory Powers Procedure Act.

The Tribunal issued the consent order, incorporating the Minutes of Settlement, which required the applicant to file audited financial statements, maintain minimum working capital, and comply with other regulatory requirements.

East Link Travel (Canada) Ltd. v. Registrar, Travel Industry Act 2002, 2013 CanLII 41662

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJun 28, 2013

Consent order issued restricting motor vehicle dealer to wholesaler class for two years.

The applicants, Ahmed Elbasiouni and VD Auto Trader Inc., and the Registrar under the Motor Vehicle Dealers Act, 2002 applied for a consent order without a hearing to resolve a Notice of Proposal to refuse and revoke registrations.

The Licence Appeal Tribunal issued the consent order, which restricted the dealer to the 'Wholesaler' class of registration for two years and imposed various compliance, disclosure, and record-keeping conditions.

Ahmed Elbasiouni and VD Auto Trader Inc. v. Registrar, Motor Vehicle Dealers Act, 2002, 2013 CanLII 41657

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJun 24, 2013

Consent order issued resolving appeal of proposal to revoke motor vehicle dealer registrations.

The applicants appealed a Notice of Proposal by the Registrar to revoke their registrations under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and applied for a consent order without a hearing under section 4.1 of the Statutory Powers Procedure Act.

The Licence Appeal Tribunal issued the consent order, incorporating the agreed terms and conditions which require the applicants to comply with the Act, cooperate with the Registrar, and pay outstanding judgments.

Charles Michael Holdings Corp. v. Registrar, Motor Vehicle Dealers Act 2002, 2013 CanLII 41473

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalMay 22, 2013

Appeal from proposal to revoke travel agency registration resolved by consent order imposing reporting conditions.

The applicant appealed a Notice of Proposal to revoke its registration under the Travel Industry Act, 2002, issued due to a failure to submit trust reconciliations.

The parties reached a settlement and requested a consent order disposing of the appeal without a hearing.

The Licence Appeal Tribunal granted the consent order, incorporating the Minutes of Settlement which required the applicant to submit monthly trust reconciliations, file annual financial statements, and maintain minimum working capital.

L & M Express Travel & Tours Inc. v. Registrar, Travel Industry Act, 2002, 2013 CanLII 29848

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalMay 6, 2013

Salesperson registration granted on consent subject to strict trading and disclosure conditions.

The applicant appealed a Notice of Proposal by the Registrar to refuse his registration as a salesperson under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and requested a consent order without a hearing under section 4.1 of the Statutory Powers Procedure Act.

The Licence Appeal Tribunal issued the consent order, granting the registration subject to strict conditions, including restrictions on trading, disclosure requirements, and a prohibition on acting as a controlling mind of a dealer.

Gainsford v. Registrar, Motor Vehicle Dealers Act 2002, 2013 CanLII 24099

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalApr 19, 2013

Consent order issued resolving appeal of motor vehicle dealer registration suspension.

The applicants appealed a Notice of Proposal by the Registrar to suspend their registration under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and applied for a consent order without a hearing pursuant to section 4.1 of the Statutory Powers Procedure Act.

The Licence Appeal Tribunal issued the consent order, incorporating terms that restrict the applicants' ability to take motor vehicles on consignment and require compliance with the Act and regulations.

1484996 Ontario Inc. o/a Stratford R.V. Centre 2001 v. Registrar, Motor Vehicle Dealers Act 2002, 2013 CanLII 21153

applicant_counsel

Katya UkrainetzCounsel
1 appearance
Self-representedSelf-represented
1 appearance

assistance for the Licensee

Alice FengAgent
1 appearance

assisted the Licensee's Representative

Rob GilroyAgent
1 appearance

assisting the Licensee

Paul MillerAgent
1 appearance

Counsel

Joy MathewsCounsel
1 appearance
Justin McLartyCounsel
1 appearance
Megan MackeyCounsel
1 appearance
Natalia PolisCounsel
1 appearance
Emily DengCounsel
1 appearance

Counsel for the Registrar

Richard KulisCounsel
1 appearance

for 1779145 Ontario Inc.

Jerry LevitanCounsel
1 appearance

for Aijia Li

Peter CopelandCounsel
1 appearance

for Clarke Chevrolet Buick GMC Ltd. and Andrew J. Clarke

Gregory G. GoulinCounsel
1 appearance

for Councillor Adam Giambrone

Chris GallopAgent
1 appearance

for herself

Julie BuckareffSelf-represented
1 appearance

for herself and on behalf of the Objectors

Rosemary UllyotSelf-represented
1 appearance

for himself

Misha GloubermanSelf-represented
2 appearances
John Bradley OrgarSelf-represented
1 appearance
Randy KerrSelf-represented
1 appearance

for himself and the Resident Objectors

Sam SilverstoneSelf-represented
1 appearance

for James A. Clarke and Heather R. Clarke

Julian PorterCounsel
1 appearance

for Milagros Tolentino

Lewis LaceronaAgent
1 appearance

for Randy Kerr

William RobertsCounsel
1 appearance

for Robert Rushlow

Andrew OstromCounsel
1 appearance

for Simcoe Condominium Corporation No. 60

Sonja HodisCounsel
1 appearance

for the Added Party

Eric DenOudenAgent
1 appearance
Charles WagmanCounsel
1 appearance
Rachel PilcCounsel
1 appearance
Jessica BraunCounsel
1 appearance
Scott NowoselskiCounsel
1 appearance
Jo-Anne BarnardAgent
1 appearance
Ron ProtockyAgent
1 appearance
Kevin ScullionCounsel
1 appearance
J. Daniel McConvilleCounsel
1 appearance

for the Appellant

Justin JakubiakCounsel
3 appearances
Ed BlahaParalegal
2 appearances
Jerry LevitanCounsel
2 appearances
Troy KaterenchukAgent
1 appearance
John RoxonAgent
1 appearance
Naresh MandaviaSelf-represented
1 appearance
Harry PerlisCounsel
1 appearance
Murray SniderCounsel
1 appearance
10549Self-represented
1 appearance
Valeria SciclunaSelf-represented
1 appearance
N.L.Self-represented
1 appearance
Vartan ManoukianParalegal
1 appearance
Jessica CanivetSelf-represented
1 appearance
Julie TremblaySelf-represented
1 appearance
Sontauna RapschParalegal
1 appearance
9626Self-represented
1 appearance
Saba AhmadCounsel
1 appearance
Gul TanisSelf-represented
1 appearance
Rajan MahavalirajanParalegal
1 appearance
Melanie BlaisSelf-represented
1 appearance

For the Appellant

AppellantSelf-represented
1 appearance

for the Appellants

Self-representedSelf-represented
1 appearance
H.S.Self-represented
1 appearance
Abdul MajeedSelf-represented
1 appearance
Peter EberhardCounsel
1 appearance
Noel GerryCounsel
1 appearance
Robert SindingCounsel
1 appearance
Justin JakubiakCounsel
1 appearance
Justin M. JakubiakCounsel
1 appearance
IOSelf-represented
1 appearance
One of the AppellantsSelf-represented
1 appearance
KLSelf-represented
1 appearance
E.C.Self-represented
1 appearance

for the applicant

Vu NguyenAgent
1 appearance

for the Applicant

David WinerAgent
4 appearances
Darlene MezzabottaParalegal
2 appearances
Kavita BoodramSelf-represented
2 appearances
Andrew FranzkeCounsel
2 appearances
Robert PlouffeAgent
2 appearances
Gareth StackhouseCounsel
2 appearances
Karen SievewrightSelf-represented
2 appearances
XianChen AnCounsel
2 appearances
Randall BarrsAgent
2 appearances
Self-representedSelf-represented
2 appearances
Megan MackeyCounsel
2 appearances
Anna IordanidiAgent
1 appearance
Charles MontgomeryAgent
1 appearance
Anna WyszomierskaAgent
1 appearance
Douglas ForsytheAgent
1 appearance
Lauren EsquivelAgent
1 appearance
Lorie HawleyAgent
1 appearance
Seema AhmadAgent
1 appearance
Li YangSelf-represented
1 appearance
Shane KelfordAgent
1 appearance

for the Applicant 2109889 Ontario Inc.

Carl CassellAgent
1 appearance

for the Applicant Mushtaq Khan

Mushtaq KhanSelf-represented
1 appearance

for the Applicants

Symon ZuckerCounsel
2 appearances
Michael SimaanCounsel
1 appearance
Yulia PesinCounsel
1 appearance
Robin SpinksCounsel
1 appearance
Sarah MolyneauxCounsel
1 appearance
Monica CaceresAgent
1 appearance
Mark ReynoldsAgent
1 appearance

for the City of Cambridge

John CosmanAgent
1 appearance

for the City of Toronto

Ray KallioAgent
4 appearances
Ray KallioCounsel
4 appearances
Jessica BraunAgent
3 appearances
Kelly MatsumotoCounsel
2 appearances
Mark CrawfordCounsel
1 appearance
Debbie CamiloAgent
1 appearance
Mark CrawfordAgent
1 appearance
Jessica BrownAgent
1 appearance
Jessica BraunCounsel
1 appearance
Sarah O'ConnorAgent
1 appearance

for the Condominium

Sonia KociperAgent
1 appearance

for the corporate licensee

Peter KavidasSelf-represented
2 appearances
Kuldeep SinghSelf-represented
2 appearances
Adam VassosCounsel
2 appearances
Boris KravetsAgent
1 appearance
John G. WilsonAgent
1 appearance
Richard KnottAgent
1 appearance
James BarkeyAgent
1 appearance
Anthony BarileCounsel
1 appearance
Spiro BoulierisSelf-represented
1 appearance
John VitulliCounsel
1 appearance
Dale HillAgent
1 appearance
Fadi HakimAgent
1 appearance
Ron FritzCounsel
1 appearance
Bruce OlmsteadCounsel
1 appearance
Clyde SmithCounsel
1 appearance
Rino YagamiSelf-represented
1 appearance
Joseph BarileCounsel
1 appearance
Flavio BattistonCounsel
1 appearance
Jeffrey AyotteAgent
1 appearance
Randall BarrsCounsel
1 appearance

for the Corporate Licensee

Randall BarrsCounsel
2 appearances
Jerry LevitanAgent
1 appearance
Noel GerryCounsel
1 appearance
Louis RajnauthAgent
1 appearance
Christopher MorrisAgent
1 appearance
Jerry LevitanCounsel
1 appearance
John LineAgent
1 appearance
Ron FritzAgent
1 appearance
Cheryl NedrickAgent
1 appearance
Suvendiran PoopalasinghamAgent
1 appearance

for the Corporate Licensee and of Sritharan Mylvaganam and Eesan Subramaniam

Jerry LevitanCounsel
1 appearance

for the Corporation

Wesley BuchnerAgent
1 appearance
Allen QiangAgent
1 appearance

for the Intervenor

Jessica BraunCounsel
2 appearances
Jo-Anne HainesAgent
1 appearance
Roger BobakSelf-represented
1 appearance
Ray KallioCounsel
1 appearance
Nellie SnowballAgent
1 appearance
Joe MurphySelf-represented
1 appearance
Kevin KokCounsel
1 appearance

for the King-Spadina Resident's Association

Wayne ScottAgent
1 appearance

for the King-Spadina Residents Association

Wayne ScottAgent
2 appearances
Don RodbardAgent
1 appearance

for the licence holder

Jerry LevitanCounsel
2 appearances
John S. FregeauCounsel
1 appearance

for the Licence Holder

Emilio BiscegliaCounsel
2 appearances
David WinerCounsel
1 appearance
Christopher WuAgent
1 appearance

for the licensee

Noel GerryCounsel
1 appearance
Mr. MariniCounsel
1 appearance
Son NguyenAgent
1 appearance
Sucha Singh MokhaAgent
1 appearance
Kevin DavisCounsel
1 appearance
Quang DuongSelf-represented
1 appearance
Calvin BarryCounsel
1 appearance
Sucha Singh MokhaSelf-represented
1 appearance
Tom MalakosAgent
1 appearance

for the Licensee

Jerry LevitanAgent
18 appearances
Jerry LevitanCounsel
17 appearances
Randall BarrsCounsel
17 appearances
Adam VassosCounsel
10 appearances
Richard ElbirtAgent
5 appearances
Harvey DennisAgent
5 appearances
Jerry HerszkopfAgent
5 appearances
Greg BurdAgent
4 appearances
Michele KhitabAgent
4 appearances
Mike FigolAgent
4 appearances
Noel GerryCounsel
3 appearances
Adam VassosAgent
3 appearances
Patrick LittleAgent
3 appearances
Patrick AllenSelf-represented
3 appearances
Randall BarrsAgent
3 appearances
John ParkCounsel
2 appearances
Pradeep ChandCounsel
2 appearances
Norman GrootCounsel
2 appearances
Chris StevensAgent
2 appearances
Ashok KumarAgent
2 appearances

for the Licensee and the Transfer Applicant

Marc KoplowitzCounsel
1 appearance

for the licensees

Fouad HakeemSelf-represented
1 appearance

for the Licensees

Kenji TsujinakaSelf-represented
1 appearance

for the Microsonic Group of Companies

Jerry LevitanAgent
1 appearance

for the Objector

Wayne ScottAgent
3 appearances
Donald RodbardAgent
1 appearance
David AstSelf-represented
1 appearance
Angela BurnsSelf-represented
1 appearance
Jeffrey WagnerSelf-represented
1 appearance
Peter ShoebridgeAgent
1 appearance

for the Objectors

Ibie DemirdacheSelf-represented
1 appearance
Terrie-Lynne DevonishSelf-represented
1 appearance
Dennis MontpetitSelf-represented
1 appearance

for the Registrant

John LeeCounsel
3 appearances
Barry WadsworthCounsel
2 appearances
Barry WadsworthAgent
2 appearances
Lisa Marie HickenSelf-represented
1 appearance
Carol KirwanSelf-represented
1 appearance
Xiang Gui ZengSelf-represented
1 appearance
Jennifer HueAgent
1 appearance
Sevag YeghoyanAgent
1 appearance
Tharsan SribalanSelf-represented
1 appearance
Michael CarolineCounsel
1 appearance
Paul GolianCounsel
1 appearance

for the Registrar

Richard KulisCounsel
61 appearances
Richard KulisAgent
48 appearances
Phillip MorrisAgent
43 appearances
Phillip MorrisCounsel
40 appearances
Sujin ChanAgent
33 appearances
Joyce TaylorAgent
30 appearances
Bryna KaplanCounsel
26 appearances
Daniel AlakasAgent
17 appearances
Joyce TaylorCounsel
15 appearances
Sujin ChanCounsel
11 appearances
Brad AltonCounsel
11 appearances
Rena KhanAgent
10 appearances
Daniel AlakasCounsel
8 appearances
Rena KhanCounsel
7 appearances
Aviva HarariAgent
6 appearances
Dan AlakasAgent
5 appearances
Tamara BrooksAgent
5 appearances
Bryna KaplanAgent
4 appearances
Lorenzo PolicelliCounsel
3 appearances
Brad AltonAgent
3 appearances

for the Registrar, Alcohol and Gaming Commission

Phillip MorrisAgent
1 appearance
Dan AlakasAgent
1 appearance
Brad AltonAgent
1 appearance
Rena KhanCounsel
1 appearance

for the Registrar of Motor Vehicles

Nora ChallisCounsel
1 appearance

for the resident objectors

Alvaro MallarinoSelf-represented
1 appearance

for the Resident Objectors

Graham JohnSelf-represented
1 appearance
Amanda JohnSelf-represented
1 appearance

for the Respondent

Rena KhanCounsel
10 appearances
Aviva HarariCounsel
5 appearances
Tamara BrooksCounsel
4 appearances
Kevin LockwoodAgent
4 appearances
Stella VelocciAgent
4 appearances
Michael RusekCounsel
4 appearances
Sonia De SantisAgent
4 appearances
Kate VarvaParalegal
4 appearances
Sanjay KapurAgent
3 appearances
Soussanna KarasCounsel
3 appearances
Victor YeeCounsel
2 appearances
Danielle PeckCounsel
2 appearances
Joyce TaylorCounsel
2 appearances
Elizabeth MaishlishCounsel
2 appearances
Maya SabharwalCounsel
2 appearances
Brian M. YungCounsel
2 appearances
Patrick MooreCounsel
2 appearances
Zahir AliCounsel
2 appearances
Connie MalloryAgent
2 appearances
Gena ArgitisCounsel
1 appearance

For the Respondent

Steve GrootenboerAgent
1 appearance

for the Respondent, Halton Standard Condominium Corporation No. 617

Jen DiasAgent
1 appearance

for the Respondent, Metropolitan Toronto Condominium Corporation No. 872

Justin McLartyCounsel
1 appearance

for the Respondent Poonam Dutta

Ian ShemeshParalegal
1 appearance

for the Respondents

Bree PierceCounsel
2 appearances
Barbara LakatosSelf-represented
1 appearance
Tae Ryung ChoiSelf-represented
1 appearance
Mi-Sug ParkSelf-represented
1 appearance
Self-representedSelf-represented
1 appearance
Daniel GreanyaParalegal
1 appearance
Carol DirksCounsel
1 appearance

for the Respondent, Silvia Yamine

Silvia YamineSelf-represented
1 appearance

for the transfer applicant

Can Zhong YaSelf-represented
1 appearance

for Toronto Standard Condominium Corporation No. 2680

Natalia PolisCounsel
1 appearance

for TriCounty Addiction Services

Sara HammelAgent
1 appearance

for Xie Lie

Patrice BandCounsel
1 appearance

Objector/Party to the proceedings

Joe ArrudaSelf-represented
1 appearance

on behalf of the licensee

Ravi CheemanlallAgent
1 appearance

on behalf of the Licensee

Cindy DouAgent
1 appearance

on her own behalf and on behalf of the objectors

Vula KawalezSelf-represented
1 appearance

On his own behalf and on behalf of the Corporate Licensee

JianPing ZhouSelf-represented
1 appearance

on his own behalf and on behalf of the objectors

Ahmed BhaiyatSelf-represented
1 appearance

on his own behalf and on behalf of the Objectors

Chris DeVitaSelf-represented
1 appearance

party to the proceeding

Stan KozakSelf-represented
1 appearance

principal of licensee

Barry AlperSelf-represented
1 appearance

Registrar's Representative

Richard KulisCounsel
1 appearance

respondent_counsel

Self-representedSelf-represented
2 appearances
Ann PipeCounsel
1 appearance

Self-represented

Houman MortazaviSelf-represented
1 appearance

Self-Represented

David D. BucklandSelf-represented
1 appearance

The Applicant

Mohit BaliSelf-represented
1 appearance
Gianni de FrancescoSelf-represented
1 appearance
Peter ChoiSelf-represented
1 appearance
Sonia Mills-MinsterSelf-represented
1 appearance
Ney CalderonSelf-represented
1 appearance
Stella KowalchukSelf-represented
1 appearance
Somkith ChaiSelf-represented
1 appearance
Kamana SubediSelf-represented
1 appearance
Margaret Ann BogueSelf-represented
1 appearance
Robert SmithSelf-represented
1 appearance
Steve MishibinijimaSelf-represented
1 appearance
Sara SeifSelf-represented
1 appearance
Marc JulienSelf-represented
1 appearance
Sarah FrenchSelf-represented
1 appearance

The Respondent

Margaret ReaAgent
1 appearance
Peter LessardAgent
1 appearance
Temesgen TirfeAgent
1 appearance
Rod EscayolaCounsel
1 appearance
Carolyn LaBatteSelf-represented
1 appearance
Luis HernandezCounsel
1 appearance
Clarence ClarkeAgent
1 appearance
John De VellisCounsel
1 appearance
Giancarlo MoscaAgent
1 appearance

The Respondents

Lewis LaceronaSelf-represented
1 appearance
Christine SapsfordSelf-represented
1 appearance

672

Decisions

Years active

Tribunals

2.9

cases/mo

AGCO429(64%)

OLAT160(24%)

OCAT74(11%)

OFSC6(1%)

OACRB3(0%)

Decision types

trial

295

motion

229

appeal

146

costs

/Adjudicator

Patricia McQuaid — Vice-Chair

Other Tribunals

Administrative Law

Real Estate Law

Statutory Accident Benefits Schedule matters (SABS)

Human Rights

Construction Law

Civil Litigation - Plaintiff

Patricia McQuaid

Vice-Chair·Condominium Authority Tribunal·Since 2007

OCAT OACRB OFSC AGCO OLAT

672

cases · 20 yrs · AGCO, OLAT, OCAT, OFSC, OACRB

Trial

Motion

Costs

Appeal

Sentencing

Vice-Chair· 391Vice-Chair· 136Vice-Chair· 34Vice Chair· 28Vice-Chair, AGCO· 19VICE -CHAIR· 11Member· 9Vice-Chair· 8

Symon Zucker

In Private Practice91 cases1985–2026

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalApr 22, 2014

Consent order issued imposing terms and conditions on motor vehicle dealer registrations in lieu of revocation.

The Registrar issued a Notice of Proposal to revoke the registrations of a motor vehicle dealership and its principals.

The parties reached a settlement and applied for a consent order without a hearing.

Switzer Motors Ltd v. Registrar, Motor Vehicle Dealers Act 2002, 2014 CanLII 23588

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalFeb 28, 2014

Consent order issued resolving appeal of proposal to revoke travel agent registration.

The parties reached a settlement and requested a consent order disposing of the appeal without a hearing.

Thames Valley Tours and Travel Inc. o/a Woodstock Travel v. Registrar, Travel Industry Act, 2002, 2014 CanLII 10708

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJan 28, 2014

Consent order issued resolving appeal of Registrar's proposal to refuse motor vehicle dealer registration.

The applicants appealed a Notice of Proposal by the Registrar to refuse their registration under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and requested a consent order without a hearing pursuant to section 4.1 of the Statutory Powers Procedure Act.

Tahir Dar v. Registrar, Motor Vehicle Dealers Act 2002, 2014 CanLII 7959

Symon Zucker

In Private Practice91 cases1985–2026

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJan 23, 2014

Consent order issued imposing conditions on motor vehicle dealer registrations to resolve revocation proposal.

The applicants appealed a Notice of Proposal by the Registrar to revoke their registrations under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and requested a consent order without a hearing pursuant to section 4.1 of the Statutory Powers Procedure Act.

Hussein Shahnematollah-Yazd and Premium Cars Wholesale Ltd v. Registrar, Motor Vehicle Dealers Act, 2002, 2014 CanLII 7974

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJan 22, 2014

Consent Order issued imposing conditions on motor vehicle dealer registration without a hearing.

The applicant appealed a Notice of Proposal by the Registrar to refuse registration under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and requested a Consent Order without a hearing.

Ramadan v. Registrar, Motor Vehicle Dealers Act 2002, 2014 CanLII 2449

Randall Barrs

80 cases2007–2025

Phillip Morris

192 cases2002–2019

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJan 13, 2014

Monetary penalty for permitting drunkenness set aside as Registrar failed to prove licensee's knowledge.

The Tribunal directed the Registrar to set aside the order of monetary penalty.

2316826 Ontario Inc. o/a Mimico Pub and Grill v. Registrar of Alcohol and Gaming, 2014 CanLII 2477

Tamara Brooks

Practising Law - Employed68 cases2010–2020

Jerry Levitan

101 cases2001–2025

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalNov 25, 2013

Liquor licence application approved subject to consent conditions after objectors withdrew their objections.

The applicant appealed a Notice of Proposal by the Registrar of Alcohol and Gaming regarding a liquor licence application.

Following a pre-hearing, the applicant and public interest objectors agreed to a set of conditions to attach to the licence.

The objectors withdrew their objections, and the Tribunal approved the liquor licence application subject to the agreed-upon conditions.

Sweet Estoril Bakery and Pastry Inc. v. Registrar of Alcohol and Gaming, 2013 CanLII 78241

Julian Porter

13 cases2002–2022

Gregory G. Goulin

1 case2013–2013

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalOct 8, 2013

Consent order issued concluding appeal of registration revocation based on 10-year undertaking not to apply.

The applicants appealed a Notice of Proposal by the Registrar to revoke their registrations as a motor vehicle dealer and salespersons.

The parties reached a settlement and requested a Consent Order without a hearing under section 4.1 of the Statutory Powers Procedure Act.

Clarke Chevrolet Buick GMC LTD. v. Registrar, Motor Vehicle Dealers Act 2002, 2013 CanLII 65429

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalOct 1, 2013

Consent order issued resolving appeal of Registrar's proposal to refuse motor vehicle dealer registration.

The applicants appealed a Notice of Proposal by the Registrar to refuse their registration under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and requested a consent order without a hearing pursuant to section 4.1 of the Statutory Powers Procedure Act.

Jainarine v. Registrar, Motor Vehicle Dealers Act 2002, 2013 CanLII 65435

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalAug 28, 2013

Consent order issued resolving appeal of proposal to revoke travel agent registration.

The Registrar issued a Notice of Proposal to revoke the registration of Happy Travellers Inc. as a travel agent for failing to maintain a trust account and file financial statements.

The applicant appealed to the Licence Appeal Tribunal.

The parties reached a settlement and requested a consent order without a hearing.

Happy Travellers Inc. v. Registrar, Travel Industry Act 2002, 2013 CanLII 58476

Evelyn Spence

Practising Law - Employed2 cases2013–2013

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJul 31, 2013

Appeal allowed; retirement home licence issued subject to agreed conditions following settlement between the parties.

The applicant appealed a Notice of Decision by the Registrar of the Retirement Homes Regulatory Authority refusing to issue a licence.

At the pre-hearing, the parties presented a settlement agreement wherein the Registrar agreed to issue the licence subject to specific conditions.

The Tribunal reviewed the agreement, confirmed the applicant's understanding and capacity to comply, and ordered the Registrar to issue the licence subject to the agreed conditions.

2321772 Ontario Inc. o/a Bel-Marine Retirement Residence v. Registrar, Retirement Homes Regulatory Authority, 2013 CanLII 51153

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJul 24, 2013

Consent order granted attaching terms and conditions to motor vehicle salesperson's registration without a hearing.

The applicant and the Registrar under the Motor Vehicle Dealers Act, 2002 applied for a consent order without a hearing pursuant to section 4.1 of the Statutory Powers Procedure Act.

Mark Lensink v. Registrar, Motor Vehicle Dealers Act, 2002, 2013 CanLII 45557

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJul 12, 2013

Consent order issued attaching conditions to a private club's liquor licence.

The applicant, The Spoke Club, and the added party, the City of Toronto, applied for a consent order without a hearing regarding the applicant's liquor licence.

The Registrar of Alcohol and Gaming took no position.

The Spoke Club v. Registrar of Alcohol and Gaming, 2013 CanLII 45549

Gena Argitis

Not Practising Law - Employed19 cases2006–2015

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJul 11, 2013

Appeal for delayed closing compensation dismissed; email notice of delay deemed effective despite postal strike.

The applicant appealed a decision by Tarion Warranty Corporation denying a claim for delayed closing compensation.

The builder had sent notice of the delay by registered mail, which was delayed due to a postal strike, and subsequently sent an email notice.

The applicant argued the email was not a permitted form of communication under the addendum and was not received.

The appeal was dismissed and the claim denied.

7995 v. Tarion, 2013 CanLII 45546

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJul 9, 2013

Consent order issued resolving appeal of travel wholesaler registration revocation upon agreed compliance terms.

The applicant appealed to the Licence Appeal Tribunal.

The parties reached a settlement and requested a consent order without a hearing under section 4.1 of the Statutory Powers Procedure Act.

East Link Travel (Canada) Ltd. v. Registrar, Travel Industry Act 2002, 2013 CanLII 41662

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJun 28, 2013

Consent order issued restricting motor vehicle dealer to wholesaler class for two years.

Ahmed Elbasiouni and VD Auto Trader Inc. v. Registrar, Motor Vehicle Dealers Act, 2002, 2013 CanLII 41657

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalJun 24, 2013

Consent order issued resolving appeal of proposal to revoke motor vehicle dealer registrations.

The applicants appealed a Notice of Proposal by the Registrar to revoke their registrations under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and applied for a consent order without a hearing under section 4.1 of the Statutory Powers Procedure Act.

Charles Michael Holdings Corp. v. Registrar, Motor Vehicle Dealers Act 2002, 2013 CanLII 41473

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalMay 22, 2013

Appeal from proposal to revoke travel agency registration resolved by consent order imposing reporting conditions.

The applicant appealed a Notice of Proposal to revoke its registration under the Travel Industry Act, 2002, issued due to a failure to submit trust reconciliations.

The parties reached a settlement and requested a consent order disposing of the appeal without a hearing.

L & M Express Travel & Tours Inc. v. Registrar, Travel Industry Act, 2002, 2013 CanLII 29848

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalMay 6, 2013

Salesperson registration granted on consent subject to strict trading and disclosure conditions.

The applicant appealed a Notice of Proposal by the Registrar to refuse his registration as a salesperson under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and requested a consent order without a hearing under section 4.1 of the Statutory Powers Procedure Act.

Gainsford v. Registrar, Motor Vehicle Dealers Act 2002, 2013 CanLII 24099

Patricia McQuaid

OLAT77 cases2007–2026

OLATOntario Licence Appeal TribunalApr 19, 2013

Consent order issued resolving appeal of motor vehicle dealer registration suspension.

The applicants appealed a Notice of Proposal by the Registrar to suspend their registration under the Motor Vehicle Dealers Act, 2002.

The parties reached a settlement and applied for a consent order without a hearing pursuant to section 4.1 of the Statutory Powers Procedure Act.

1484996 Ontario Inc. o/a Stratford R.V. Centre 2001 v. Registrar, Motor Vehicle Dealers Act 2002, 2013 CanLII 21153

Page 11 of 34 (672 cases)

applicant_counsel

Katya UkrainetzCounsel
1 appearance
Self-representedSelf-represented
1 appearance

assistance for the Licensee

Alice FengAgent
1 appearance

assisted the Licensee's Representative

Rob GilroyAgent
1 appearance

assisting the Licensee

Paul MillerAgent
1 appearance

Counsel

Joy MathewsCounsel
1 appearance
Justin McLartyCounsel
1 appearance
Megan MackeyCounsel
1 appearance
Natalia PolisCounsel
1 appearance
Emily DengCounsel
1 appearance

Counsel for the Registrar

Richard KulisCounsel
1 appearance

for 1779145 Ontario Inc.

Jerry LevitanCounsel
1 appearance

for Aijia Li

Peter CopelandCounsel
1 appearance

for Clarke Chevrolet Buick GMC Ltd. and Andrew J. Clarke

Gregory G. GoulinCounsel
1 appearance

for Councillor Adam Giambrone

Chris GallopAgent
1 appearance

for herself

Julie BuckareffSelf-represented
1 appearance

for herself and on behalf of the Objectors

Rosemary UllyotSelf-represented
1 appearance

for himself

Misha GloubermanSelf-represented
2 appearances
John Bradley OrgarSelf-represented
1 appearance
Randy KerrSelf-represented
1 appearance

for himself and the Resident Objectors

Sam SilverstoneSelf-represented
1 appearance

for James A. Clarke and Heather R. Clarke

Julian PorterCounsel
1 appearance

for Milagros Tolentino

Lewis LaceronaAgent
1 appearance

for Randy Kerr

William RobertsCounsel
1 appearance

for Robert Rushlow

Andrew OstromCounsel
1 appearance

for Simcoe Condominium Corporation No. 60

Sonja HodisCounsel
1 appearance

for the Added Party

Eric DenOudenAgent
1 appearance
Charles WagmanCounsel
1 appearance
Rachel PilcCounsel
1 appearance
Jessica BraunCounsel
1 appearance
Scott NowoselskiCounsel
1 appearance
Jo-Anne BarnardAgent
1 appearance
Ron ProtockyAgent
1 appearance
Kevin ScullionCounsel
1 appearance
J. Daniel McConvilleCounsel
1 appearance

for the Appellant

Justin JakubiakCounsel
3 appearances
Ed BlahaParalegal
2 appearances
Jerry LevitanCounsel
2 appearances
Troy KaterenchukAgent
1 appearance
John RoxonAgent
1 appearance
Naresh MandaviaSelf-represented
1 appearance
Harry PerlisCounsel
1 appearance
Murray SniderCounsel
1 appearance
10549Self-represented
1 appearance
Valeria SciclunaSelf-represented
1 appearance
N.L.Self-represented
1 appearance
Vartan ManoukianParalegal
1 appearance
Jessica CanivetSelf-represented
1 appearance
Julie TremblaySelf-represented
1 appearance
Sontauna RapschParalegal
1 appearance
9626Self-represented
1 appearance
Saba AhmadCounsel
1 appearance
Gul TanisSelf-represented
1 appearance
Rajan MahavalirajanParalegal
1 appearance
Melanie BlaisSelf-represented
1 appearance

For the Appellant

AppellantSelf-represented
1 appearance

for the Appellants

Self-representedSelf-represented
1 appearance
H.S.Self-represented
1 appearance
Abdul MajeedSelf-represented
1 appearance
Peter EberhardCounsel
1 appearance
Noel GerryCounsel
1 appearance
Robert SindingCounsel
1 appearance
Justin JakubiakCounsel
1 appearance
Justin M. JakubiakCounsel
1 appearance
IOSelf-represented
1 appearance
One of the AppellantsSelf-represented
1 appearance
KLSelf-represented
1 appearance
E.C.Self-represented
1 appearance

for the applicant

Vu NguyenAgent
1 appearance

for the Applicant

David WinerAgent
4 appearances
Darlene MezzabottaParalegal
2 appearances
Kavita BoodramSelf-represented
2 appearances
Andrew FranzkeCounsel
2 appearances
Robert PlouffeAgent
2 appearances
Gareth StackhouseCounsel
2 appearances
Karen SievewrightSelf-represented
2 appearances
XianChen AnCounsel
2 appearances
Randall BarrsAgent
2 appearances
Self-representedSelf-represented
2 appearances
Megan MackeyCounsel
2 appearances
Anna IordanidiAgent
1 appearance
Charles MontgomeryAgent
1 appearance
Anna WyszomierskaAgent
1 appearance
Douglas ForsytheAgent
1 appearance
Lauren EsquivelAgent
1 appearance
Lorie HawleyAgent
1 appearance
Seema AhmadAgent
1 appearance
Li YangSelf-represented
1 appearance
Shane KelfordAgent
1 appearance

for the Applicant 2109889 Ontario Inc.

Carl CassellAgent
1 appearance

for the Applicant Mushtaq Khan

Mushtaq KhanSelf-represented
1 appearance

for the Applicants

Symon ZuckerCounsel
2 appearances
Michael SimaanCounsel
1 appearance
Yulia PesinCounsel
1 appearance
Robin SpinksCounsel
1 appearance
Sarah MolyneauxCounsel
1 appearance
Monica CaceresAgent
1 appearance
Mark ReynoldsAgent
1 appearance

for the City of Cambridge

John CosmanAgent
1 appearance

for the City of Toronto

Ray KallioAgent
4 appearances
Ray KallioCounsel
4 appearances
Jessica BraunAgent
3 appearances
Kelly MatsumotoCounsel
2 appearances
Mark CrawfordCounsel
1 appearance
Debbie CamiloAgent
1 appearance
Mark CrawfordAgent
1 appearance
Jessica BrownAgent
1 appearance
Jessica BraunCounsel
1 appearance
Sarah O'ConnorAgent
1 appearance

for the Condominium

Sonia KociperAgent
1 appearance

for the corporate licensee

Peter KavidasSelf-represented
2 appearances
Kuldeep SinghSelf-represented
2 appearances
Adam VassosCounsel
2 appearances
Boris KravetsAgent
1 appearance
John G. WilsonAgent
1 appearance
Richard KnottAgent
1 appearance
James BarkeyAgent
1 appearance
Anthony BarileCounsel
1 appearance
Spiro BoulierisSelf-represented
1 appearance
John VitulliCounsel
1 appearance
Dale HillAgent
1 appearance
Fadi HakimAgent
1 appearance
Ron FritzCounsel
1 appearance
Bruce OlmsteadCounsel
1 appearance
Clyde SmithCounsel
1 appearance
Rino YagamiSelf-represented
1 appearance
Joseph BarileCounsel
1 appearance
Flavio BattistonCounsel
1 appearance
Jeffrey AyotteAgent
1 appearance
Randall BarrsCounsel
1 appearance

for the Corporate Licensee

Randall BarrsCounsel
2 appearances
Jerry LevitanAgent
1 appearance
Noel GerryCounsel
1 appearance
Louis RajnauthAgent
1 appearance
Christopher MorrisAgent
1 appearance
Jerry LevitanCounsel
1 appearance
John LineAgent
1 appearance
Ron FritzAgent
1 appearance
Cheryl NedrickAgent
1 appearance
Suvendiran PoopalasinghamAgent
1 appearance

for the Corporate Licensee and of Sritharan Mylvaganam and Eesan Subramaniam

Jerry LevitanCounsel
1 appearance

for the Corporation

Wesley BuchnerAgent
1 appearance
Allen QiangAgent
1 appearance

for the Intervenor

Jessica BraunCounsel
2 appearances
Jo-Anne HainesAgent
1 appearance
Roger BobakSelf-represented
1 appearance
Ray KallioCounsel
1 appearance
Nellie SnowballAgent
1 appearance
Joe MurphySelf-represented
1 appearance
Kevin KokCounsel
1 appearance

for the King-Spadina Resident's Association

Wayne ScottAgent
1 appearance

for the King-Spadina Residents Association

Wayne ScottAgent
2 appearances
Don RodbardAgent
1 appearance

for the licence holder

Jerry LevitanCounsel
2 appearances
John S. FregeauCounsel
1 appearance

for the Licence Holder

Emilio BiscegliaCounsel
2 appearances
David WinerCounsel
1 appearance
Christopher WuAgent
1 appearance

for the licensee

Noel GerryCounsel
1 appearance
Mr. MariniCounsel
1 appearance
Son NguyenAgent
1 appearance
Sucha Singh MokhaAgent
1 appearance
Kevin DavisCounsel
1 appearance
Quang DuongSelf-represented
1 appearance
Calvin BarryCounsel
1 appearance
Sucha Singh MokhaSelf-represented
1 appearance
Tom MalakosAgent
1 appearance

for the Licensee

Jerry LevitanAgent
18 appearances
Jerry LevitanCounsel
17 appearances
Randall BarrsCounsel
17 appearances
Adam VassosCounsel
10 appearances
Richard ElbirtAgent
5 appearances
Harvey DennisAgent
5 appearances
Jerry HerszkopfAgent
5 appearances
Greg BurdAgent
4 appearances
Michele KhitabAgent
4 appearances
Mike FigolAgent
4 appearances
Noel GerryCounsel
3 appearances
Adam VassosAgent
3 appearances
Patrick LittleAgent
3 appearances
Patrick AllenSelf-represented
3 appearances
Randall BarrsAgent
3 appearances
John ParkCounsel
2 appearances
Pradeep ChandCounsel
2 appearances
Norman GrootCounsel
2 appearances
Chris StevensAgent
2 appearances
Ashok KumarAgent
2 appearances

for the Licensee and the Transfer Applicant

Marc KoplowitzCounsel
1 appearance

for the licensees

Fouad HakeemSelf-represented
1 appearance

for the Licensees

Kenji TsujinakaSelf-represented
1 appearance

for the Microsonic Group of Companies

Jerry LevitanAgent
1 appearance

for the Objector

Wayne ScottAgent
3 appearances
Donald RodbardAgent
1 appearance
David AstSelf-represented
1 appearance
Angela BurnsSelf-represented
1 appearance
Jeffrey WagnerSelf-represented
1 appearance
Peter ShoebridgeAgent
1 appearance

for the Objectors

Ibie DemirdacheSelf-represented
1 appearance
Terrie-Lynne DevonishSelf-represented
1 appearance
Dennis MontpetitSelf-represented
1 appearance

for the Registrant

John LeeCounsel
3 appearances
Barry WadsworthCounsel
2 appearances
Barry WadsworthAgent
2 appearances
Lisa Marie HickenSelf-represented
1 appearance
Carol KirwanSelf-represented
1 appearance
Xiang Gui ZengSelf-represented
1 appearance
Jennifer HueAgent
1 appearance
Sevag YeghoyanAgent
1 appearance
Tharsan SribalanSelf-represented
1 appearance
Michael CarolineCounsel
1 appearance
Paul GolianCounsel
1 appearance

for the Registrar

Richard KulisCounsel
61 appearances
Richard KulisAgent
48 appearances
Phillip MorrisAgent
43 appearances
Phillip MorrisCounsel
40 appearances
Sujin ChanAgent
33 appearances
Joyce TaylorAgent
30 appearances
Bryna KaplanCounsel
26 appearances
Daniel AlakasAgent
17 appearances
Joyce TaylorCounsel
15 appearances
Sujin ChanCounsel
11 appearances
Brad AltonCounsel
11 appearances
Rena KhanAgent
10 appearances
Daniel AlakasCounsel
8 appearances
Rena KhanCounsel
7 appearances
Aviva HarariAgent
6 appearances
Dan AlakasAgent
5 appearances
Tamara BrooksAgent
5 appearances
Bryna KaplanAgent
4 appearances
Lorenzo PolicelliCounsel
3 appearances
Brad AltonAgent
3 appearances

for the Registrar, Alcohol and Gaming Commission

Phillip MorrisAgent
1 appearance
Dan AlakasAgent
1 appearance
Brad AltonAgent
1 appearance
Rena KhanCounsel
1 appearance

for the Registrar of Motor Vehicles

Nora ChallisCounsel
1 appearance

for the resident objectors

Alvaro MallarinoSelf-represented
1 appearance

for the Resident Objectors

Graham JohnSelf-represented
1 appearance
Amanda JohnSelf-represented
1 appearance

for the Respondent

Rena KhanCounsel
10 appearances
Aviva HarariCounsel
5 appearances
Tamara BrooksCounsel
4 appearances
Kevin LockwoodAgent
4 appearances
Stella VelocciAgent
4 appearances
Michael RusekCounsel
4 appearances
Sonia De SantisAgent
4 appearances
Kate VarvaParalegal
4 appearances
Sanjay KapurAgent
3 appearances
Soussanna KarasCounsel
3 appearances
Victor YeeCounsel
2 appearances
Danielle PeckCounsel
2 appearances
Joyce TaylorCounsel
2 appearances
Elizabeth MaishlishCounsel
2 appearances
Maya SabharwalCounsel
2 appearances
Brian M. YungCounsel
2 appearances
Patrick MooreCounsel
2 appearances
Zahir AliCounsel
2 appearances
Connie MalloryAgent
2 appearances
Gena ArgitisCounsel
1 appearance

For the Respondent

Steve GrootenboerAgent
1 appearance

for the Respondent, Halton Standard Condominium Corporation No. 617

Jen DiasAgent
1 appearance

for the Respondent, Metropolitan Toronto Condominium Corporation No. 872

Justin McLartyCounsel
1 appearance

for the Respondent Poonam Dutta

Ian ShemeshParalegal
1 appearance

for the Respondents

Bree PierceCounsel
2 appearances
Barbara LakatosSelf-represented
1 appearance
Tae Ryung ChoiSelf-represented
1 appearance
Mi-Sug ParkSelf-represented
1 appearance
Self-representedSelf-represented
1 appearance
Daniel GreanyaParalegal
1 appearance
Carol DirksCounsel
1 appearance

for the Respondent, Silvia Yamine

Silvia YamineSelf-represented
1 appearance

for the transfer applicant

Can Zhong YaSelf-represented
1 appearance

for Toronto Standard Condominium Corporation No. 2680

Natalia PolisCounsel
1 appearance

for TriCounty Addiction Services

Sara HammelAgent
1 appearance

for Xie Lie

Patrice BandCounsel
1 appearance

Objector/Party to the proceedings

Joe ArrudaSelf-represented
1 appearance

on behalf of the licensee

Ravi CheemanlallAgent
1 appearance

on behalf of the Licensee

Cindy DouAgent
1 appearance

on her own behalf and on behalf of the objectors

Vula KawalezSelf-represented
1 appearance

On his own behalf and on behalf of the Corporate Licensee

JianPing ZhouSelf-represented
1 appearance

on his own behalf and on behalf of the objectors

Ahmed BhaiyatSelf-represented
1 appearance

on his own behalf and on behalf of the Objectors

Chris DeVitaSelf-represented
1 appearance

party to the proceeding

Stan KozakSelf-represented
1 appearance

principal of licensee

Barry AlperSelf-represented
1 appearance

Registrar's Representative

Richard KulisCounsel
1 appearance

respondent_counsel

Self-representedSelf-represented
2 appearances
Ann PipeCounsel
1 appearance

Self-represented

Houman MortazaviSelf-represented
1 appearance

Self-Represented

David D. BucklandSelf-represented
1 appearance

The Applicant

Mohit BaliSelf-represented
1 appearance
Gianni de FrancescoSelf-represented
1 appearance
Peter ChoiSelf-represented
1 appearance
Sonia Mills-MinsterSelf-represented
1 appearance
Ney CalderonSelf-represented
1 appearance
Stella KowalchukSelf-represented
1 appearance
Somkith ChaiSelf-represented
1 appearance
Kamana SubediSelf-represented
1 appearance
Margaret Ann BogueSelf-represented
1 appearance
Robert SmithSelf-represented
1 appearance
Steve MishibinijimaSelf-represented
1 appearance
Sara SeifSelf-represented
1 appearance
Marc JulienSelf-represented
1 appearance
Sarah FrenchSelf-represented
1 appearance

The Respondent

Margaret ReaAgent
1 appearance
Peter LessardAgent
1 appearance
Temesgen TirfeAgent
1 appearance
Rod EscayolaCounsel
1 appearance
Carolyn LaBatteSelf-represented
1 appearance
Luis HernandezCounsel
1 appearance
Clarence ClarkeAgent
1 appearance
John De VellisCounsel
1 appearance
Giancarlo MoscaAgent
1 appearance

The Respondents

Lewis LaceronaSelf-represented
1 appearance
Christine SapsfordSelf-represented
1 appearance

672

Decisions

Years active

Tribunals

2.9

cases/mo

AGCO429(64%)

OLAT160(24%)

OCAT74(11%)

OFSC6(1%)

OACRB3(0%)

Decision types

trial

295

motion

229

appeal

146

costs

Page 11 of 34 (672 cases)