The defendant, Attorney General of Canada, brought a motion for summary judgment to dismiss the plaintiff contractor's claim for additional compensation related to alleged delays and extra work on a construction project.
The court found that the plaintiff failed to comply with the strict notice provisions of the contract, which barred its claims.
The court also rejected the plaintiff's arguments that the defendant waived strict compliance with the contract or that the plaintiff was entitled to compensation based on quantum meruit or unjust enrichment.
The motion for summary judgment was granted and the action was dismissed.
