D. Resnick

The defendant brought an unsuccessful motion for summary judgment to dismiss the plaintiff's multi-million dollar construction delay claim.

The court determined that the summary judgment motion was a bold and risky tactical strategy in a complex case where a trial was inevitable.

The plaintiff was awarded partial indemnity costs for the main summary judgment motion and the related leave motion, while the defendant was awarded costs for a successful production motion, resulting in a net costs award of $145,878.62 payable to the plaintiff.

The defendant general contractor brought a motion for summary judgment to dismiss the plaintiff subcontractor's $11.1 million delay claim, arguing the plaintiff failed to provide strict contractual notice of the delay.

The plaintiff argued that the defendant had actual notice and that strict compliance was not required given the surrounding circumstances.

The court dismissed the motion, finding that the issues of notice, credibility regarding backdated letters, and the complex factual matrix of the construction delay raised genuine issues requiring a full trial.