K. Thavaraj

Schindler Elevator Corporation brought an action to perfect a construction lien for unpaid services and materials supplied for the installation of elevators at the Women's College Hospital redevelopment project.

The general contractor, Walsh Construction/Bondfield Partnership (WBP), counterclaimed for delay impact losses, liquidated damages, and indemnification for penalties, alleging Schindler's delayed performance critically impacted the project schedule.

The court found that while Schindler breached the subcontract by delayed performance, WBP failed to prove that Schindler's delays impacted the critical path of the project or caused the majority of the claimed damages.

Schindler was awarded judgment for the unpaid subcontract balance, less minor set-offs for direct impacts, and WBP's claims against Schindler and its surety, Zurich, were dismissed.

In a pre-trial motion regarding the admissibility of trial affidavit evidence, the moving party sought to strike the entirety of an affidavit.

The moving party argued the affidavit contained inadmissible, irrelevant, and opinion evidence without proper foundation.

The Master found that while the affiant had personal knowledge of certain communications, substantial portions of the affidavit lacked foundational knowledge or contained improper legal interpretation and argument.

The Master ordered specific paragraphs struck but admitted the remainder of the affidavit.

The plaintiff, Schindler Elevator Corporation, moved for the production of fully unredacted minutes of settlement between the defendants (WBP) and a third party (Yuanda).

WBP had produced a partially redacted version, claiming settlement privilege over the financial terms.

The court found that while the specific settlement amounts should remain privileged, other redacted information relevant to the apportionment of delay and quantification of damages must be disclosed to ensure procedural fairness at the upcoming trial.

The court ordered WBP to produce a further version of the minutes with only the specific settlement amounts and payment dates redacted.